Concurrent delay
Concurrent delay is a complex term, the legal status of which remains unclear.
Delays on a project will have different contractual consequences depending on the cause of the delay:
- Where a delay which impacts on the completion date is caused by the contractor (culpable delay), the contractor may be liable to pay liquidated and ascertained damages (LADs) to the client.
- Where a delay which impacts the completion date is not caused by either the contractor or the client, the contractor may be entitled to an extension of time.
- Where a delay is caused by the client, the contractor may be able to claim an extension of time and loss and expense.
Concurrent delay refers to the complex situation where more than one event occurs at the same time, but where not all of those events enable the contractor to claim an extension of time or to claim loss and expense.
As it is rare for events to happen at precisely the same time, concurrent delay is sometimes defined as ‘Two or more delay events occurring within the same time period, each independently affecting the Completion Date’ (Judge Seymour - Royal Brompton Hospital National Health Trust v Hammond and Others), or where the events may have happened at different times, but their effects (at least in part) are felt concurrently.
The difficulty arises in determining whether concurrent delays allow an extension of time and loss and expense claims, or liquidated and ascertained damages.
For example, the contractor may already have been delayed through their own fault, when another event occurs for which the client is at fault.
In the case of Royal Brompton Hospital National Health Trust v Hammond and Others, Judge Seymour stated that concurrent delay did not mean ’ …a situation in which, work already being delayed, let it be supposed, because the contractor has had difficulty in obtaining sufficient labour, an event occurs which is a Relevant Event and which, had the contractor not been delayed would have caused him to be delayed, but which in fact, by reason of the existing delay, made no difference.’
In this scenario, the event did not in fact impact on the completion date, which was already delayed by the contractor. Where this is not the case – for example, in the case of Walter Lilly & Company Ltd v Giles Patrick Cyrill Mackay, it was considered that ‘ …provided the relevant events can be shown to have delayed the works, the contractor is entitled to an extension of time for the whole period of delay caused by the relevant events. There is nothing to suggest an extension should be reduced if the causation criterion is established.’
In the case of City Inn v Shepherd Construction, The Scottish Appeal Court decided that apportioning delay was appropriate where there was no dominant cause of delay. They concluded that:
- The relevant event must delay or be likely to delay the works.
- If a dominant cause can be identified, this must be the relevant event.
- If no dominant cause can be identified, an apportionment should be made in a fair and reasonable way.
However, if the client contributes to an event, then they may not be entitled to liquidated and ascertained damages. For example, in the case of Peak Construction v McKinney Foundations, the judge ruled ‘... I cannot see how, in the ordinary course, the employer can insist on compliance with a condition if it is partly his own fault that it cannot be fulfilled…’
Furthermore, in Henry Boot Construction v Malmaison Hotel it was ruled that ‘…to take a simple example, if no work is possible on a site for a week not only because of exceptionally inclement weather (a relevant event) but also because the contractor has a shortage of labour (not a relevant event) and if the failure to work during that week is likely to delay the works beyond the completion date by one week, then if it considers it fair and reasonable to do so, the architect is required to grant an extension of time of one week. He cannot refuse to do so on the grounds that the delay would have occurred in any event by reason of the shortage of labour.'
The situation is complex, and cases tend each to have circumstances that are unique in some way. Furthermore, cases of concurrent delay do not often reach the courts as they tend to be settled through alternative dispute resolution procedures. The resulting uncertainty is compounded by the differences in wording between various contract types.
Keating states that ‘..a proper analysis of entitlement to extension of time and any associated loss and expense in each case must involve a careful consideration of the wording of the relevant clauses and an assessment of the (possibly different) tests of causation that should be applied to them in order for the contractor’s actual entitlement to be arrived at.’
What is clear is that it is important for both parties to ensure they keep good records to demonstrate that the event did actually occur and that it did impact on the completion date. If it is possible to carry out a critical path analysis that demonstrates the effect of events on the completion date, then this is beneficial, however, in the absence of such information it is likely that the courts will take a ‘common sense’ approach.
[edit] Related articles on Designing Buildings Wiki
- Alternative Dispute Resolution.
- Certificate of non-completion.
- Culpable delay.
- Compensation event.
- Completion date.
- Contractor delay.
- Extension of time.
- Liquidated and ascertained damages.
- Loss and expense.
- Reasonable time.
- Relevant event.
- Royal Brompton Hospital National Health Trust v Hammond and Others.
Featured articles and news
The continued ISG fall out, where to go?
Support for ISG contractors, companies and employees.
New HES national centre for traditional building retrofit
Announced as HES publishes survey results which reveal strong support for retrofit.
Retrofit of Buildings, a CIOB Technical Publication
Expected to become one of the largest activities in the global construction industry.
The ECA industry focus video channel
Keeping update with the industry session by session.
Over 25 recorded informations sessions freely available.
AT Awards 2024 ceremony East London October 25th.
Revisiting the AT community at the 2023 awards evening.
The Community Housing Fund and built affordable homes
CLTN reviews the impact of the Fund and calls for extension.
The grading system of the Regulator for Social Housing
A background, an explanation and ten recent enforcements.
Construction, repair and maintenance. Book review.
Putting new life into a city with a 1900 year history.
BSRIA Briefing 2024: Sustainable Futures speakers
Redefining Retrofit for Net Zero Living 22 Nov.
Wall of support for post-Grenfell regulation of electricians
Call for a shake-up of the construction industry highlighted on radio.
Digital sustainability through future AEC tools
Bringing together industry and academia to meet challenges.
Skills gap for net zero highlighted to Minister for Industry
ECA convenes roundtable discussion at Portcullis House.
Evidencing Net Zero with the new UK buildings standard
Pilot version with detailed excel proforma out now!
Scottish Building Safety Levy, in consultation
From direct remediation and the RPDT, to the costs and alternatives.
Waves of warmer homes grants for the rental sector
Boosting energy efficiency standards for all rented homes.
A refocus of the National Planning Policy Framework
Key terms described in brief, as the consultation closes the evening of the 24th.
Fortified farmhouses of the unruly 16th-and 17th-century borders.